Terms & Conditions

These Terms & Conditions govern your use of this website and any services provided by Axis Studio. By using the website, submitting an inquiry, booking a consultation, approving a proposal, or paying an invoice, you agree to these terms unless a signed agreement states otherwise.

Axis Studio business details should be completed before launch: [Business Registration Details], [Business Address], and [Jurisdiction].

Axis Studio provides digital launch services including website design and development, branding, booking system setup, payment setup, CRM or database setup, email automation, admin dashboards, e-commerce setup, and launch support.

Specific deliverables, timelines, fees, revision rounds, payment schedule, and responsibilities will be set out in a proposal, statement of work, invoice, or written agreement.

Clients are responsible for providing accurate information, timely feedback, brand assets, content, access credentials, legal details, platform approvals, and any required third-party accounts.

Delays in providing feedback, content, approvals, payments, or access may affect timelines and delivery dates.

Fees, deposits, milestones, and due dates will be stated in the relevant proposal or invoice. Work may not begin until required deposits or initial payments are received.

Late payments may pause work, delay launch, or result in additional fees where allowed by law and agreed in writing.

Once final payment is received, the client receives ownership of approved final deliverables created specifically for the client, unless otherwise stated.

Axis Studio retains ownership of pre-existing materials, frameworks, processes, templates, know-how, code patterns, and non-client-specific tools used to deliver the project.

Projects may rely on platforms such as hosting providers, payment gateways, booking tools, CRMs, analytics tools, email platforms, or plugin providers.

Axis Studio is not responsible for outages, pricing changes, account restrictions, feature removals, or policy decisions made by third-party platforms.

To the fullest extent permitted by law, Axis Studio is not liable for indirect, incidental, special, consequential, or loss-of-profit damages arising from website use or service engagement.

Axis Studio's total liability for a project will not exceed the fees paid by the client for the specific service giving rise to the claim, unless applicable law requires otherwise.

These terms are governed by the laws of [Jurisdiction]. Any disputes will be handled in the courts or dispute resolution process applicable in [Jurisdiction], unless a written agreement states otherwise.